STANDARD TERMS AND CONDITIONS OF SALE

Corbell Projects LLC

Licensed & Insured | MRSR5403 | MRSA5381 | IICRC WRT #70214938

By accepting an estimate, authorizing services, or engaging Corbell Projects LLC (“Contractor”), the customer (“Client”) agrees to the following legally binding terms and conditions:

1. Scope of Work

All services will be performed in accordance with the approved written estimate or work order. Any deviation from the original scope, discovery of hidden damage, or customer-requested changes may result in additional charges and revised project timelines. Any changes must be authorized in writing.

2. Licensing & Regulatory Compliance

Corbell Projects LLC is fully licensed and insured in the State of Florida to perform mold remediation and assessment services under the Department of Business and Professional Regulation (DBPR):

• Mold Remediator License: MRSR5403

• Mold Assessor License: MRSA5381

• IICRC Certified in Water Damage Restoration (WRT #70214938)

All services are provided in compliance with applicable Florida statutes, DBPR rules, IICRC guidelines, and relevant EPA and OSHA standards.

3. Access to Property

The Client agrees to provide safe, unrestricted, and timely access to the property for scheduled inspections, services, and equipment pick-up. If access is not granted during scheduled timeframes, additional charges may apply, including but not limited to travel fees, standby time, or rescheduling costs. Corbell Projects LLC is not liable for project delays due to access restrictions or third-party interference.

4. Payment Terms

Unless otherwise agreed in writing:

• Full payment is due upon job completion.

• Invoices not paid within fifteen (15) calendar days of the invoice date will incur a 5% late fee.

• Returned or failed payments (NSF) will incur a $35 processing fee.

• A deposit may be required for certain jobs prior to scheduling.

Failure to pay may result in collections, project delays, or the filing of a lien in accordance with Florida law. All legal costs incurred in recovering unpaid balances shall be the responsibility of the Client.

5. Cancellation & Rescheduling

Cancellations or reschedules must be communicated at least 24 hours in advance of the scheduled visit. If a technician is dispatched and service is denied, canceled onsite, or access is not provided, a $85 Diagnostic & Travel Fee will be applied. Repeated cancellations may result in service suspension.

6. Property Conditions & Hidden Damages

All inspections are visual unless otherwise stated. Corbell Projects LLC is not responsible for hidden, latent, or pre-existing damages. If previously unseen conditions are discovered during service, work may be paused, and a revised estimate will be submitted for approval before continuing.

7. Use of Equipment

When drying, remediation, or air purification equipment is installed:

• Equipment is typically left onsite for three (3) days unless otherwise agreed.

• Equipment must not be moved, disconnected, tampered with, or turned off by the Client or occupants.

• Unauthorized handling may result in damage fees, service failure, or liability for property damage.

• Equipment lost, stolen, or damaged during the rental period will be billed to the Client at replacement value.

8. Environmental & Mold Services

All mold testing, assessments, and remediation work are performed in accordance with Florida Statutes Chapter 468, Part XVI.

• Reports, lab results, and air quality data will only be released to the Client, authorized property manager, or insurer.

• Results will not be shared with tenants or unauthorized individuals under any circumstances without prior written authorization.

• Services involving microbial growth will be described as “discoloration” or “suspected microbial growth” in compliance with regulatory language unless confirmed by a licensed assessor.

9. Warranties & Limitations of Liability

Corbell Projects LLC guarantees that all work will be performed in a professional and workmanlike manner.

• No other warranties, expressed or implied, are made.

• Liability is limited to the total amount paid for the specific services rendered.

• Corbell Projects LLC shall not be held responsible for delays, consequential damages, loss of use, or damage due to force majeure, vendor delays, access issues, or acts of nature.

10. Dispute Resolution

This agreement is governed by the laws of the State of Florida.

• Any claim or dispute arising out of this agreement shall be resolved in the courts of Orange County, Florida.

• The parties agree to attempt good faith mediation prior to pursuing formal legal action.

• Corbell Projects LLC reserves the right to recover reasonable legal fees and collection costs incurred in the enforcement of these terms.

11. Photographs & Video Documentation

To maintain quality, transparency, and compliance, Corbell Projects LLC may take photographs or videos of the service areas before, during, and after completion.

• These materials are used strictly for professional purposes including reporting, insurance documentation, quality control, technician training, internal audits, or marketing (anonymized).

• Photos and videos taken by our team remain the exclusive property of Corbell Projects LLC.

 Clients and tenants are strictly prohibited from recording or photographing Corbell Projects LLC staff or technicians without prior written consent. Unauthorized recording or publication may constitute a violation of privacy rights and result in legal consequences.

12. Use of Media & Data

Any media or documentation produced by Corbell Projects LLC may not be edited, altered, or distributed without written permission. Clients authorize the Contractor to use anonymized images for marketing or internal purposes, provided no identifying information or personal data is revealed.